抖阴短视频

Works Contract for Philippines

Works Contract Template for Philippines

A comprehensive legal agreement governed by Philippine law that establishes the terms and conditions for construction or infrastructure works between a project owner and a contractor. This document incorporates requirements from the Civil Code of the Philippines, the National Building Code, and relevant construction industry regulations, detailing the scope of works, payment terms, timelines, quality standards, and compliance requirements. It includes provisions for worker safety under Philippine labor laws and environmental compliance, while addressing specific local regulatory requirements and construction practices unique to the Philippine context.

Your data doesn't train Genie's AI

You keep IP ownership聽of your information

Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.

Download a Standard Template

4.6 / 5
4.8 / 5
Access for free
OR

Alternatively: Run an advanced review of an existing
Works Contract

Let 抖阴短视频's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.

What is a Works Contract?

The Works Contract is a fundamental document in the Philippine construction industry, essential for any project involving construction, renovation, or infrastructure development. This contract type is specifically designed to comply with Philippine legal requirements, including the Civil Code, National Building Code, and Construction Industry Authority of the Philippines (CIAP) regulations. It is typically used when engaging contractors for construction projects, ranging from building developments to infrastructure works, and includes comprehensive provisions for scope definition, payment structures, timelines, quality standards, and regulatory compliance. The document addresses unique aspects of Philippine construction law, including local permitting requirements, workers' rights under Philippine labor law, and environmental regulations. It serves as a crucial tool for project owners and contractors to establish clear terms, allocate risks, and ensure smooth project execution while maintaining compliance with local legal frameworks.

What sections should be included in a Works Contract?

1. Parties: Identification of the Employer and the Contractor, including their complete legal names, addresses, and registration details

2. Background: Context of the agreement, including brief project overview and basis for entering into the contract

3. Definitions and Interpretation: Definitions of key terms used throughout the contract and rules for interpreting the agreement

4. Scope of Works: Detailed description of the construction works to be performed, including specific deliverables and objectives

5. Contract Price and Payment Terms: Amount payable for the works, payment schedule, method of payment, and conditions for payment

6. Timeline and Completion: Project schedule, completion dates, milestones, and provisions for extensions of time

7. Contractor's Obligations: Key responsibilities including workforce, materials, equipment, safety standards, and compliance with laws

8. Employer's Obligations: Responsibilities including site access, permits, approvals, and provision of necessary information

9. Quality and Standards: Required quality standards, inspection procedures, and acceptance criteria

10. Variations: Process for handling changes to scope, pricing, or timeline of works

11. Health, Safety and Environment: Requirements for workplace safety, environmental protection, and compliance with regulations

12. Insurance and Indemnity: Required insurance coverage and indemnification obligations of both parties

13. Defects Liability: Duration of defects liability period and obligations for rectifying defects

14. Termination: Grounds and procedures for contract termination by either party

15. Dispute Resolution: Process for resolving disputes, including mediation and arbitration procedures

16. General Provisions: Standard clauses including notices, governing law, entire agreement, and amendments

What sections are optional to include in a Works Contract?

1. Performance Security: Required when the project value exceeds certain thresholds or when specifically requested by the Employer

2. Advance Payment: Included when advance payments are to be made, specifying terms and security requirements

3. Subcontracting: Required when subcontracting is permitted, specifying conditions and approval requirements

4. Equipment and Materials Supply: Included when specific arrangements exist for supply of materials or equipment by the Employer

5. Force Majeure: Detailed provisions for force majeure events, particularly relevant in areas prone to natural disasters

6. Intellectual Property Rights: Required when the works involve design elements or proprietary technology

7. Site Conditions: Included when there are specific site-related risks or conditions that need addressing

8. Testing and Commissioning: Required for projects involving mechanical or electrical installations

What schedules should be included in a Works Contract?

1. Schedule 1 - Scope of Works: Detailed technical specifications, drawings, and work descriptions

2. Schedule 2 - Project Timeline: Detailed project schedule, milestones, and completion dates

3. Schedule 3 - Bill of Quantities: Itemized list of quantities, unit rates, and prices

4. Schedule 4 - Payment Schedule: Detailed breakdown of payment terms, milestones, and amounts

5. Schedule 5 - Technical Specifications: Detailed technical requirements and standards for materials and workmanship

6. Schedule 6 - Site Information: Site details, access points, existing conditions, and restrictions

7. Schedule 7 - Forms and Certificates: Standard forms for variations, completion certificates, and other project documents

8. Schedule 8 - Insurance Requirements: Detailed insurance requirements including types, coverage amounts, and special conditions

9. Appendix A - Required Permits and Licenses: List of required regulatory approvals and permits

10. Appendix B - Health and Safety Requirements: Detailed safety procedures and requirements

Authors

Alex Denne

Head of Growth (Open Source Law) @ 抖阴短视频 | 3 x UCL-Certified in Contract Law & Drafting | 4+ Years Managing 1M+ Legal Documents | Serial Founder & Legal AI Author

Jurisdiction

Philippines

Document Type

Employment Contract

Cost

Free to use
Relevant legal definitions


















































Clauses











































Relevant Industries

Construction

Infrastructure

Real Estate Development

Mining

Manufacturing

Energy

Telecommunications

Transportation

Industrial Development

Public Works

Commercial Development

Residential Development

Relevant Teams

Legal

Operations

Procurement

Construction

Project Management

Commercial

Risk and Compliance

Finance

Technical Services

Business Development

Property Development

Relevant Roles

Project Manager

Construction Manager

Contract Administrator

Legal Counsel

Chief Executive Officer

Operations Director

Procurement Manager

Site Engineer

Quantity Surveyor

Risk Manager

Commercial Director

Development Manager

Technical Director

Compliance Officer

Finance Director

Industries










Teams

Employer, Employee, Start Date, Job Title, Department, Location, Probationary Period, Notice Period, Salary, Overtime, Vacation Pay, Statutory Holidays, Benefits, Bonus, Expenses, Working Hours, Rest Breaks, 聽Leaves of Absence, Confidentiality, Intellectual Property, Non-Solicitation, Non-Competition, Code of Conduct, Termination, 聽Severance Pay, Governing Law, Entire Agreemen

Find the exact document you need

Standard Employment Contract For Filipino Domestic Worker

Standard employment contract for Filipino domestic workers, compliant with Philippine Kasambahay Law and labor regulations, outlining employment terms and conditions.

find out more

Employee Agreement Bond

A Philippine-law governed agreement establishing terms for employee training investment and service commitment, with provisions for bond repayment if service terms are not met.

find out more

Employment Contract For Kitchen Staff

Philippine-compliant employment contract template for kitchen staff positions, covering essential terms and food service industry requirements.

find out more

Standard Work Contract

A standard employment agreement governed by Philippine law that establishes the formal employer-employee relationship and outlines essential employment terms and conditions.

find out more

Simple Work Contract

A standard employment agreement compliant with Philippine labor laws, establishing basic terms and conditions between employer and employee.

find out more

Preliminary Employment Contract

A preliminary employment agreement under Philippine law establishing initial terms and conditions between employer and prospective employee.

find out more

Piece Work Agreement In (Construction)

A Philippine law-compliant agreement establishing piece-rate payment terms between contractors and workers for specific construction tasks.

find out more

Housemaid Contract Agreement

A Philippine law-compliant employment agreement between household employers and domestic workers under the Kasambahay Law, establishing terms and conditions of domestic employment.

find out more

Hiring Contract

A Philippine law-compliant employment agreement establishing terms and conditions between employer and employee.

find out more

Employer Arbitration Agreement

A Philippine-compliant Employer Arbitration Agreement establishing procedures for resolving employment disputes through binding arbitration.

find out more

Contract Forlance Work

A Philippine law-compliant freelance work contract establishing terms of engagement between clients and independent contractors under RA 11915.

find out more

Contract For Trainee Employee

A Philippine law-compliant agreement establishing terms and conditions for trainee employment, including training program details and employment conditions.

find out more

Labour Employment Contract

A legally binding employment agreement that establishes employment terms and conditions under Philippine law and labor regulations.

find out more

Employment Contract For Restaurant Staff

Philippine-compliant employment contract template for restaurant staff, covering essential terms and food service industry requirements.

find out more

Valid Employment Contract

A legally binding employment agreement that establishes employment terms and conditions in compliance with Philippine labor laws.

find out more

Pharmacist Employment Agreement

A comprehensive employment agreement for licensed pharmacists in the Philippines, compliant with Philippine Pharmacy Act and Labor Code requirements.

find out more

One Year Fixed Term Contract

A Philippine law-compliant Fixed Term Employment Contract establishing a one-year employment relationship with defined terms and conditions.

find out more

Part Time Work Agreement

A Philippine law-compliant agreement establishing terms and conditions for part-time employment, including work hours, compensation, and statutory benefits.

find out more

Regular Employment Contract

Philippine-law governed employment contract establishing permanent employment terms and conditions, compliant with local labor regulations.

find out more

Short Employment Contract

A streamlined employment agreement compliant with Philippine labor laws, establishing basic terms of employment and statutory requirements.

find out more

Unlimited Employment Contract

A permanent employment contract compliant with Philippine labor laws, establishing an indefinite employment relationship with full statutory benefits and protections.

find out more

2 Year Fixed Term Contract

A two-year fixed-term employment contract template compliant with Philippine labor laws and regulations.

find out more

Contractual Employee Contract

A Philippine-compliant fixed-term employment contract establishing terms and conditions for contractual employment relationships.

find out more

On Hire Labour Agreement

A Philippine-law governed agreement establishing employment terms between a labor hire company, worker, and client company, ensuring compliance with local labor laws and DOLE regulations.

find out more

Seafarer Employment Agreement

A Philippine-law governed employment agreement for seafarers working on international vessels, compliant with POEA and international maritime standards.

find out more

Renewable Contract Of Employment

A Philippine-compliant employment contract establishing fixed-term employment with renewal provisions, adhering to local labor laws and DOLE regulations.

find out more

Re Employment Contract

A Philippine law-governed contract establishing renewed employment terms between an employer and former employee, compliant with the Philippine Labor Code.

find out more

Project Based Employment Contract

A Philippine law-compliant fixed-term employment agreement for project-based work that defines project scope, duration, and terms of engagement.

find out more

Physician Employment Agreement

A Philippine law-governed agreement establishing employment terms between a healthcare facility and a physician, ensuring compliance with local medical and labor regulations.

find out more

Physician Contract

A Philippine-compliant employment agreement between a healthcare facility and a physician, outlining professional terms and obligations under Philippine medical and labor laws.

find out more

One Year Contract Employment Letter

A Philippine-law compliant employment letter establishing a one-year fixed-term employment relationship, detailing terms, conditions, and benefits.

find out more

Official Employment Contract

A standardized employment agreement compliant with Philippine labor laws, establishing terms and conditions of employment between employer and employee.

find out more

Nail Salon Employee Contract

A Philippine-law compliant employment contract for nail salon workers, covering essential terms, conditions, and industry-specific requirements.

find out more

Non Fixed Term Employment Contract

Standard indefinite term employment contract template compliant with Philippine labor laws and regulations.

find out more

Labour Hire Agreement

A Philippine-law governed agreement between a labor hire company and client company for the provision of workers, ensuring compliance with local labor regulations and DOLE requirements.

find out more

Individual Employment Contract

A Philippine law-compliant employment contract establishing terms and conditions between employer and employee.

find out more

Indefinite Term Labor Contract

A Philippine law-compliant indefinite term employment agreement establishing a regular employment relationship with statutory benefits and protections.

find out more

Fixed Term Employment Agreement

A comprehensive Fixed Term Employment Agreement compliant with Philippine labor laws, establishing defined-period employment terms and conditions.

find out more

Full Time Job Contract

A full-time employment contract compliant with Philippine labor laws, establishing terms and conditions of employment between employer and employee.

find out more

Contract For Contractual Employees

Philippine-compliant employment agreement for contractual workers, establishing terms and conditions for fixed-term or project-based employment.

find out more
See more related templates

骋别苍颈别鈥檚 Security Promise

Genie is the safest place to draft. Here鈥檚 how we prioritise your privacy and security.

Your documents are private:

We do not train on your data; 骋别苍颈别鈥檚 AI improves independently

All data stored on Genie is private to your organisation

Your documents are protected:

Your documents are protected by ultra-secure 256-bit encryption

We are ISO27001 certified, so your data is secure

Organizational security:

You retain IP ownership of your documents and their information

You have full control over your data and who gets to see it