Ƶ

Building Contract Agreement for Singapore

Building Contract Agreement Template for Singapore

A comprehensive legal agreement governed by Singapore law that establishes the rights, obligations, and responsibilities between an employer and a contractor for construction works. The document incorporates requirements under the Building Control Act, Building and Construction Industry Security of Payment Act, and other relevant Singapore legislation. It details scope of works, payment terms, completion timelines, quality standards, and dispute resolution mechanisms while ensuring compliance with BCA regulations and industry standards.

Your data doesn't train Genie's AI

You keep IP ownership of your information

Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.

Download a Standard Template

4.6 / 5
4.8 / 5
Access for free
OR

Alternatively: Run an advanced review of an existing
Building Contract Agreement

Let Ƶ's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.

What is a Building Contract Agreement?

The Building Contract Agreement is a fundamental document in Singapore's construction industry, used to formalize the relationship between parties involved in construction projects. It ensures compliance with Singapore's Building Control Act and related regulations while protecting the interests of both employer and contractor. This document is essential for any construction project, providing clear terms on scope, payment, timelines, and quality standards. It incorporates Singapore's specific requirements for building safety, environmental protection, and worker welfare, while establishing mechanisms for project management and dispute resolution.

What sections should be included in a Building Contract Agreement?

1. Parties: Identification of the Employer and Contractor, including full legal names and registered addresses

2. Background: Context of the agreement, including project overview and purpose

3. Definitions: Key terms used throughout the contract and their specific meanings

4. Scope of Works: Detailed description of construction works to be performed

5. Contract Sum and Payment Terms: Price, payment schedule, and payment conditions

6. Time for Completion: Project timeline, completion date, and milestone dates

7. Contractor's Obligations: Key responsibilities and duties of the contractor

8. Employer's Obligations: Key responsibilities and duties of the employer

9. Variations: Process for handling changes to scope or specifications

10. Insurance and Indemnity: Required insurance coverage and indemnification provisions

What sections are optional to include in a Building Contract Agreement?

1. Performance Bond: Security for performance of contract obligations - typically used for high-value projects or when required by employer

2. Liquidated Damages: Pre-agreed damages for delay or non-performance - used when specific completion dates are critical

3. Defects Liability Period: Period during which contractor must remedy defects - standard in most building contracts but duration may vary

4. Assignment and Subcontracting: Rights and restrictions regarding third-party involvement - used when subcontractors are likely to be involved

What schedules should be included in a Building Contract Agreement?

1. Schedule of Works: Detailed specifications and drawings of the works

2. Schedule of Rates: Breakdown of costs and rates for different elements

3. Project Timeline: Detailed project schedule with milestones

4. Technical Specifications: Detailed technical requirements and standards

5. Insurance Requirements: Specific insurance policies and coverage required

6. Quality Assurance Plan: Standards and procedures for quality control

7. Safety Requirements: Safety protocols and requirements

8. Forms and Certificates: Standard forms for variations, completion certificates, etc.

Authors

Alex Denne

Head of Growth (Open Source Law) @ Ƶ | 3 x UCL-Certified in Contract Law & Drafting | 4+ Years Managing 1M+ Legal Documents | Serial Founder & Legal AI Author

Jurisdiction

Singapore

Publisher

Ƶ

Cost

Free to use
Relevant legal definitions






































Clauses



































Industries

Building Control Act (Chapter 29): Primary legislation governing building works, structural requirements, and building control in Singapore

Building Control Regulations: Detailed regulations supporting the Building Control Act, specifying technical requirements and procedures

Building Maintenance and Strata Management Act: Legislation governing the proper maintenance of buildings and common property management

Building and Construction Authority Act: Establishes the BCA and its powers to regulate the construction industry

Planning Act: Controls land use and development in Singapore

Building and Construction Industry Security of Payment Act: Facilitates payments for construction work and related goods and services

Workplace Safety and Health Act: Ensures safety, health, and welfare of persons at work in construction sites

Environmental Protection and Management Act: Regulates environmental protection and pollution control in construction activities

Fire Safety Act: Governs fire safety requirements in buildings and construction works

Contract Law: Common law principles governing formation and enforcement of contracts in Singapore

Unfair Contract Terms Act: Regulates unfair terms in contracts and limits the extent to which liability can be excluded

Limitation Act: Sets time limits for bringing legal actions relating to contractual disputes

BCA Builder Licensing Framework: Guidelines for licensing of builders and contractors in Singapore

PSSCOC for Construction Works: Standard conditions of contract used in public sector construction projects

SIA Building Contract: Standard form of building contract published by Singapore Institute of Architects

REDAS Design and Build Conditions: Standard conditions for design and build contracts by Real Estate Developers' Association

Singapore Standards (SS): Technical standards and specifications for construction works in Singapore

Employment Act: Basic terms and working conditions for workers in Singapore

Work Injury Compensation Act: Governs compensation for workplace injuries in construction projects

Employment of Foreign Manpower Act: Regulates employment of foreign workers in construction industry

Arbitration Act: Framework for arbitration as a dispute resolution mechanism

Mediation Act: Provides framework for mediation proceedings in construction disputes

Teams

Employer, Employee, Start Date, Job Title, Department, Location, Probationary Period, Notice Period, Salary, Overtime, Vacation Pay, Statutory Holidays, Benefits, Bonus, Expenses, Working Hours, Rest Breaks,  Leaves of Absence, Confidentiality, Intellectual Property, Non-Solicitation, Non-Competition, Code of Conduct, Termination,  Severance Pay, Governing Law, Entire Agreemen

Find the exact document you need

Subcontractor Service Agreement

A Singapore-law governed agreement defining terms and conditions for subcontractor services, including scope, payment, and compliance requirements.

find out more

Subcontractor Employment Agreement

A Singapore-law governed agreement establishing terms and conditions between a company and subcontractor for provision of services.

find out more

Sole Trader Contract

A Singapore-law governed contract establishing the legal framework for sole trader business operations and compliance requirements.

find out more

Simple Subcontractor Contract

A Singapore-law governed agreement between contractor and subcontractor defining work scope, terms, and obligations.

find out more

Simple Payment Agreement Contract

A Singapore law-governed agreement establishing payment terms and obligations between parties.

find out more

Residential Contractor Agreement

A legally binding agreement under Singapore law between property owners and contractors for residential construction or renovation works.

find out more

Pre Agreement Contract

A Singapore-law governed preliminary agreement that sets the framework for negotiations and protects parties' interests during deal discussions.

find out more

Painting Contract Agreement

A Singapore-compliant contract governing painting services, defining terms between contractor and client.

find out more

Independent Contractor And Non Compete

A Singapore-law governed agreement establishing independent contractor terms and non-compete obligations.

find out more

Foreign Independent Contractor Agreement

A Singapore law-governed agreement establishing terms between a Singapore-based company and a foreign independent contractor.

find out more

Driver Contractor Agreement

A Singapore-compliant legal agreement establishing the relationship between a transportation service provider and an independent driver contractor.

find out more

Domestic Subcontract Agreement

A Singapore-governed agreement between main contractor and subcontractor for construction works.

find out more

Contractor Service Agreement

A Singapore law-governed agreement establishing terms between contractors and clients for professional services provision.

find out more

Contractor Referral Agreement

A Singapore-law governed agreement establishing terms for contractor referrals, including commission structures and referral processes.

find out more

Contract For Personal Service

A Singapore-governed agreement establishing terms between an independent contractor and client for provision of professional services.

find out more

Contract For Labor Agreement

A legally binding employment agreement for manual labor workers in Singapore, compliant with local labor laws and workplace regulations.

find out more

Contract Between Employer And Independent Contractor

A Singapore-law governed agreement establishing terms between a business and independent contractor, defining service scope, payment terms, and relationship parameters.

find out more

Consulting Agreement Contract

A Singapore-law governed agreement establishing terms and conditions between a consultant and client for professional services delivery.

find out more

Construction Contractor Contract

A Singapore-law governed agreement between principal and contractor for construction works, incorporating local building regulations and industry standards.

find out more

Civil Work Contract Agreement

A Singapore-compliant contract governing civil construction works between an employer and contractor, outlining terms, conditions, and obligations.

find out more

Subcontractor Hold Harmless Agreement

A Singapore-law governed agreement establishing indemnification obligations between contractor and subcontractor, protecting the principal contractor from liability arising from subcontractor's work.

find out more

Salon Contract For Employees

A Singapore-compliant employment contract specifically designed for salon staff, establishing terms of employment and professional standards in the beauty industry.

find out more

Part Time Contractor Agreement

A Singapore-law governed agreement establishing terms for part-time contractor services, ensuring clear distinction from employment relationship.

find out more

Mining Contractor Agreement

A Singapore-law governed agreement between mining companies and contractors for mining services, incorporating local regulatory requirements.

find out more

Home Remodel Contract

A Singapore-governed contract for residential renovation works, establishing terms between homeowner and contractor.

find out more

Framework Agreement Contract

A Singapore-law governed agreement establishing terms for ongoing procurement relationships and future contracts.

find out more

Construction Warranty Agreement

A legally binding agreement under Singapore law that guarantees construction quality and outlines warranty obligations for defects and repairs.

find out more

Construction Service Contract

A legal agreement for construction services in Singapore, governing contractor-client relationships and ensuring compliance with local construction laws.

find out more

Contract Agreement Between Two Parties

A customizable legal agreement between two parties under Singapore law, establishing mutual terms and obligations without standardized constraints.

find out more

Construction Contract Agreement Form

A standardized construction agreement under Singapore law establishing terms and conditions for building projects.

find out more

Binding Agreement Contract

A legally binding contract governed by Singapore law that establishes enforceable terms and conditions between parties.

find out more

Agreement Security Guard Contract

A Singapore-law governed contract establishing terms for security guard services, compliant with PSIA regulations.

find out more

Agreement For Construction Of House

A Singapore law-governed agreement setting out terms and conditions for house construction, including scope, payments, and responsibilities.

find out more

Agreement Between Contractor And Principal Employer

A Singapore-law governed agreement establishing terms between a principal employer and independent contractor, defining services, payments, and obligations.

find out more

Independent Contractor Equity Agreement

A Singapore-law governed agreement establishing independent contractor status and equity compensation terms for services provided to a company.

find out more

Model Form Contract

A standardized contract template compliant with Singapore law, designed for efficient business transactions.

find out more

Company Bond Contract

A Singapore-law governed agreement documenting terms and conditions of corporate bond issuance, establishing rights and obligations between issuer and bondholders.

find out more

Construction Owner's Representative Contract

A Singapore law-governed agreement appointing a professional representative to oversee construction projects on behalf of the property owner.

find out more

Profit Sharing Agreement Independent Contractor

A Singapore-governed agreement establishing profit-sharing terms between an independent contractor and a business entity.

find out more

Loan Officer Independent Contractor Agreement

A Singapore-governed agreement establishing terms between financial institutions and independent contractor loan officers, ensuring regulatory compliance and defining service parameters.

find out more
See more related templates

ұԾ’s Security Promise

Genie is the safest place to draft. Here’s how we prioritise your privacy and security.

Your documents are private:

We do not train on your data; ұԾ’s AI improves independently

All data stored on Genie is private to your organisation

Your documents are protected:

Your documents are protected by ultra-secure 256-bit encryption

We are ISO27001 certified, so your data is secure

Organizational security:

You retain IP ownership of your documents and their information

You have full control over your data and who gets to see it