Ƶ

Fixed Price Building Contract for India

Fixed Price Building Contract Template for India

A comprehensive construction agreement governed by Indian law that establishes a fixed-price arrangement between an employer/owner and a contractor for the execution of specific building works. This contract type provides certainty in project costs by setting a predetermined price for the entire scope of work, subject to strictly controlled variation mechanisms. The document incorporates relevant Indian construction laws, including RERA compliance where applicable, and addresses key aspects such as quality standards, timelines, payment terms, defect liability, and dispute resolution procedures specific to the Indian legal context.

Your data doesn't train Genie's AI

You keep IP ownership of your information

Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.

Download a Standard Template

4.6 / 5
4.8 / 5
Access for free
OR

Alternatively: Run an advanced review of an existing
Fixed Price Building Contract

Let Ƶ's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.

What is a Fixed Price Building Contract?

The Fixed Price Building Contract is a specialized construction agreement designed for use in the Indian market where parties seek price certainty in their construction projects. It is particularly suitable for well-defined construction projects where the scope, specifications, and drawings are sufficiently detailed at the outset. The document incorporates requirements under Indian construction laws, including the Real Estate (Regulation and Development) Act 2016, relevant labor laws, and environmental regulations. It provides comprehensive coverage of project execution parameters, quality standards, payment mechanisms, and risk allocation while maintaining the fixed-price nature of the arrangement. This contract type is widely used in both private and public sector construction projects across India, offering protection to both employers and contractors through clear delineation of responsibilities and robust dispute resolution mechanisms.

What sections should be included in a Fixed Price Building Contract?

1. Parties: Identification and details of the Employer/Owner and the Contractor

2. Background: Context of the construction project and the parties' intention to enter into this agreement

3. Definitions and Interpretation: Definitions of key terms used throughout the contract and rules of interpretation

4. Scope of Work: Detailed description of the construction work to be carried out by the Contractor

5. Contract Price: Fixed price for the entire project, including payment terms, schedule, and mechanisms for price adjustment if applicable

6. Project Timeline: Construction schedule, completion date, and milestones

7. Contractor's Obligations: Comprehensive list of Contractor's duties, responsibilities, and warranties

8. Employer's Obligations: Responsibilities of the Employer including site access, approvals, and information provision

9. Quality and Standards: Required quality standards, materials specifications, and workmanship requirements

10. Supervision and Inspection: Rights and procedures for supervision, inspection, and approval of work

11. Variations: Process for handling changes to the scope of work and their impact on price and timeline

12. Insurance and Indemnity: Required insurance coverage and indemnification obligations

13. Defects Liability: Defects liability period and procedures for rectification of defects

14. Force Majeure: Provisions for handling unforeseen circumstances and their impact on the contract

15. Termination: Grounds and procedures for contract termination by either party

16. Dispute Resolution: Procedures for resolving disputes, including arbitration provisions

17. Governing Law and Jurisdiction: Applicable law and jurisdiction for the contract

What sections are optional to include in a Fixed Price Building Contract?

1. Performance Security: Requirements for performance bank guarantees or other security - include for high-value projects

2. Liquidated Damages: Pre-determined damages for delay or non-performance - include when specific completion timing is crucial

3. Environmental Compliance: Specific environmental obligations - include for projects with significant environmental impact

4. Labor Compliance: Detailed labor law compliance requirements - include for large workforce projects

5. Site Security: Specific security requirements - include for sensitive or high-risk locations

6. Intellectual Property Rights: IP rights in designs and documents - include for projects involving unique designs

7. Confidentiality: Confidentiality obligations - include for projects involving sensitive information

8. Step-in Rights: Employer's right to take over work - include for critical infrastructure projects

9. Anti-corruption Provisions: Specific anti-corruption compliance - include for public sector or high-value projects

What schedules should be included in a Fixed Price Building Contract?

1. Schedule 1 - Technical Specifications: Detailed technical specifications for all aspects of construction

2. Schedule 2 - Drawings and Plans: Approved architectural and engineering drawings

3. Schedule 3 - Bill of Quantities: Detailed breakdown of quantities and rates

4. Schedule 4 - Payment Schedule: Milestone-based payment schedule with amounts

5. Schedule 5 - Project Timeline: Detailed construction schedule with milestones

6. Schedule 6 - Quality Assurance Plan: Detailed quality control and assurance procedures

7. Schedule 7 - List of Approved Materials: Specifications and brands of approved construction materials

8. Schedule 8 - Forms of Certificates: Templates for various certificates including completion certificates

9. Schedule 9 - Insurance Requirements: Detailed insurance specifications and coverage requirements

10. Schedule 10 - Site Details: Site layout, access points, and existing conditions

11. Appendix A - Statutory Approvals: Copies of all relevant permits and approvals

12. Appendix B - Safety Manual: Safety procedures and protocols to be followed

Authors

Alex Denne

Head of Growth (Open Source Law) @ Ƶ | 3 x UCL-Certified in Contract Law & Drafting | 4+ Years Managing 1M+ Legal Documents | Serial Founder & Legal AI Author

Jurisdiction

India

Publisher

Ƶ

Cost

Free to use
Relevant legal definitions






















































Clauses














































Relevant Industries

Real Estate Development

Commercial Construction

Residential Construction

Industrial Construction

Infrastructure Development

Healthcare Facilities

Educational Institutions

Hospitality

Retail Development

Manufacturing Facilities

Warehousing and Logistics

Public Sector Construction

Relevant Teams

Legal

Construction

Commercial

Procurement

Finance

Operations

Project Management

Technical

Risk and Compliance

Quality Assurance

Business Development

Contract Administration

Relevant Roles

Project Director

Construction Manager

Contract Manager

Legal Counsel

Procurement Manager

Chief Engineer

Project Architect

Financial Controller

Risk Manager

Commercial Director

Technical Director

Compliance Officer

Cost Manager

Quality Assurance Manager

Site Supervisor

Operations Director

Development Manager

Industries










Teams

Employer, Employee, Start Date, Job Title, Department, Location, Probationary Period, Notice Period, Salary, Overtime, Vacation Pay, Statutory Holidays, Benefits, Bonus, Expenses, Working Hours, Rest Breaks,  Leaves of Absence, Confidentiality, Intellectual Property, Non-Solicitation, Non-Competition, Code of Conduct, Termination,  Severance Pay, Governing Law, Entire Agreemen

Find the exact document you need

Lien Contract

An Indian law-governed agreement establishing a lien right over specified property as security for an underlying obligation.

find out more

Labour Contract Form

A standardized employment agreement compliant with Indian labor laws, establishing terms and conditions of employment between employer and employee.

find out more

House Wiring Contract

An Indian law-governed contract for electrical wiring installation services, specifying technical requirements, safety standards, and compliance with Indian electrical regulations.

find out more

Handyman Maintenance Contract

An Indian law-governed agreement between a handyman/maintenance service provider and property owner/manager, outlining maintenance services, terms, and obligations.

find out more

General Contract

A versatile contract template under Indian law that establishes formal business relationships between parties, compliant with the Indian Contract Act and related legislation.

find out more

Contractor Non Compete Agreement

An Indian law-compliant agreement restricting a contractor's competitive activities during their engagement period, protecting company interests while maintaining enforceability under Section 27 of the Indian Contract Act.

find out more

Contractor Lien Release

An Indian legal document where a contractor waives their right to place a lien on a property after receiving payment for work performed or materials supplied.

find out more

Contract With Builder

An Indian law-governed agreement between property owner and builder for construction works, compliant with RERA and construction regulations.

find out more

Contractors Agreement Form

An Indian law-governed agreement establishing terms and conditions between a hiring entity and a contractor, defining their professional relationship and mutual obligations.

find out more

Conditions Of Contract For (Construction)

Standard construction contract conditions template under Indian law governing rights, obligations, and procedures for construction projects in India.

find out more

Construction Agreement Contract

An Indian law-governed agreement between property owner/developer and contractor establishing terms for construction works, including scope, payments, and compliance requirements.

find out more

Basic Independent Contractor Agreement

An Indian law-governed agreement establishing the terms and conditions between a company and an independent contractor, defining service scope, payment terms, and contractor status.

find out more

Architect Contract Agreement

An Indian law-governed agreement between an architect/architectural firm and client, defining architectural services, fees, and mutual obligations.

find out more

Simple Contract Labor Agreement

An Indian law-compliant agreement between a Principal Employer and Contractor for the provision and management of contract labor services.

find out more

Private Security Contract

An Indian law-governed agreement for private security services provision, compliant with PSARA 2005 and related regulations.

find out more

Payment Contract Agreement

An Indian law-governed agreement establishing payment terms, schedules, and obligations between parties, ensuring compliant and secure monetary transactions.

find out more

Contractor Work Contract

An India-compliant Contractor Work Contract establishing terms and conditions for independent contractor services, including scope, payment, and deliverables.

find out more

Building Construction Labour Contract Agreement

An Indian jurisdiction labor contract agreement for construction projects, establishing terms between principal employers and labor contractors while ensuring compliance with local construction and labor laws.

find out more

Developer Contractor Agreement

An Indian law-governed agreement establishing terms for engaging an independent developer contractor, including service scope, payments, and IP rights.

find out more

Standard Form Of Agreement Between Owner And Contractor

An Indian law-governed agreement between property owner and contractor defining construction project terms, obligations, and deliverables.

find out more

Turnkey Contract

An Indian law-governed contract for the complete design, construction, and delivery of a fully operational facility, where the contractor assumes total responsibility from design through commissioning.

find out more

Time And Materials Contract

An Indian law-governed agreement for charging based on actual time spent and materials used in project delivery, including rates, tracking, and approval processes.

find out more

Standard Renovation Contract

An Indian law-governed contract establishing terms and conditions for property renovation works between owners and contractors.

find out more

Swimming Pool Contract

An Indian law-governed contract for swimming pool construction and installation, detailing specifications, responsibilities, and compliance requirements.

find out more

Suppliers Contract Agreement

An Indian law-governed agreement establishing terms and conditions between a purchaser and supplier for the provision of goods or services.

find out more

Service Contract Proposal

An Indian law-compliant Service Contract Proposal template outlining service arrangements, terms, and obligations between parties under Indian jurisdiction.

find out more

Residential Solar Installation Contract

An Indian law-governed contract for residential solar power system installation, covering technical specifications, warranties, and regulatory compliance.

find out more

Restoration Contract

An Indian law-governed contract specifying terms and conditions for property restoration work, including scope, specifications, timelines, and compliance requirements.

find out more

Receipt Contract

A legally binding document under Indian law that provides formal evidence of a financial transaction or transfer of goods/services, compliant with Indian Contract Act and GST regulations.

find out more

Real Estate Contractor Agreement

An Indian law-governed agreement between property owner/developer and contractor establishing terms and conditions for construction services, including scope, payments, and compliance requirements.

find out more

Proposal And Contract

An Indian law-governed document combining a business proposal with binding contractual terms, establishing commercial and legal parameters for business relationships.

find out more

Owner's Representative Contract

An Indian law-governed agreement appointing a representative to act on behalf of a property owner, defining their authority, responsibilities, and compensation.

find out more

Masonry Contract

An Indian law-governed contract establishing terms and conditions for masonry construction work, including quality standards, specifications, and compliance requirements.

find out more

Marketing Agreement Contract

An Indian law-governed agreement establishing terms between a marketing service provider and client for marketing services delivery, including scope, payments, and compliance requirements.

find out more

Lump Sum Contract

An Indian law-governed fixed-price contract establishing terms for project delivery at a predetermined lump sum amount, with defined scope and milestone-based payments.

find out more

Insurance Agency Agreement

An Indian law-governed agreement establishing the relationship between an insurance company and its agent, compliant with IRDAI regulations.

find out more

Labour Only Subcontractor Agreement

Indian law-compliant agreement template for engaging labor-only subcontractors, ensuring compliance with local labor regulations and statutory requirements.

find out more

Kitchen Renovation Contract

An Indian law-governed contract for kitchen renovation projects, defining scope, terms, and obligations between contractors and property owners.

find out more

Kitchen Contract

An Indian law-governed agreement for kitchen construction or renovation services, outlining project specifications, terms, and obligations of all parties involved.

find out more

Labour Supply Contract

An Indian law-governed agreement between a labor contractor and principal employer for the supply and management of contract workers.

find out more
See more related templates

ұԾ’s Security Promise

Genie is the safest place to draft. Here’s how we prioritise your privacy and security.

Your documents are private:

We do not train on your data; ұԾ’s AI improves independently

All data stored on Genie is private to your organisation

Your documents are protected:

Your documents are protected by ultra-secure 256-bit encryption

We are ISO27001 certified, so your data is secure

Organizational security:

You retain IP ownership of your documents and their information

You have full control over your data and who gets to see it