The Building Construction Contract Agreement is a fundamental legal document used in the Canadian construction industry to establish a binding relationship between project owners and contractors. This agreement is essential for any construction project where a building or structure is being erected, renovated, or significantly modified. It must comply with federal regulations such as the National Building Code of Canada, as well as provincial legislation including the Construction Act, Occupational Health and Safety Act, and local building codes. The contract addresses critical elements including scope of work, payment terms, construction timeline, change order procedures, warranties, and dispute resolution mechanisms. It's designed to protect both parties' interests while ensuring clear communication and risk allocation throughout the construction process.
Your data doesn't train Genie's AI
You keep IP ownership of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let Ƶ's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
1. Parties: Identification and details of the Owner and Contractor
2. Background: Context of the construction project and purpose of the agreement
3. Definitions: Defined terms used throughout the agreement
4. Scope of Work: Detailed description of the construction work to be performed
5. Contract Price and Payment: Payment terms, schedule, and mechanisms including holdbacks
6. Project Timeline: Construction schedule, milestones, and completion dates
7. Contractor's Obligations: Key responsibilities including labor, materials, permits, and compliance
8. Owner's Obligations: Access to site, approvals, and owner-supplied materials or information
9. Site Conditions and Safety: Site management, safety protocols, and environmental requirements
10. Changes and Delays: Process for change orders and handling of delays
11. Insurance and Indemnity: Required insurance coverage and indemnification provisions
12. Warranties and Defects: Warranty terms and defect correction procedures
13. Termination: Grounds and procedures for contract termination
14. Dispute Resolution: Process for resolving disputes including mediation and arbitration
15. General Provisions: Standard legal provisions including notices, assignment, and governing law
1. Financing Arrangements: Terms related to project financing when external funding is involved
2. Phased Completion: Specific provisions for projects with multiple completion phases
3. Specialized Work: Additional terms for specialized construction elements or techniques
4. Environmental Compliance: Detailed environmental requirements for environmentally sensitive projects
5. Heritage Conservation: Special provisions for projects involving heritage buildings
6. Multiple Prime Contractors: Coordination requirements when multiple prime contractors are involved
7. Value Engineering: Procedures for cost optimization suggestions during construction
8. Commissioning: Detailed commissioning requirements for complex systems
9. Building Information Modeling: BIM requirements and protocols when applicable
1. Schedule A - Construction Drawings: Approved architectural and engineering drawings
2. Schedule B - Technical Specifications: Detailed technical requirements and standards
3. Schedule C - Price Breakdown: Detailed breakdown of the contract price
4. Schedule D - Construction Schedule: Detailed timeline with milestones and critical path
5. Schedule E - Required Insurance: Specific insurance requirements and coverage limits
6. Schedule F - Forms: Standard forms for change orders, payment applications, etc.
7. Schedule G - Site Plan: Detailed site plan showing work areas and access
8. Schedule H - Permits and Approvals: List of required permits and approval status
9. Schedule I - Quality Control Program: Quality control procedures and requirements
10. Appendix 1 - Health and Safety Plan: Detailed safety procedures and protocols
11. Appendix 2 - Environmental Management Plan: Environmental protection measures and procedures
Authors
Relevant legal definitions
Clauses
Relevant Industries
Commercial Real Estate
Residential Construction
Industrial Construction
Infrastructure Development
Institutional Buildings
Healthcare Facilities
Educational Facilities
Retail Development
Hospitality
Mixed-Use Development
Relevant Teams
Legal
Finance
Operations
Procurement
Risk Management
Project Management
Construction Management
Quality Assurance
Health and Safety
Technical Services
Commercial
Relevant Roles
Construction Project Manager
Contract Administrator
Legal Counsel
Chief Financial Officer
Project Director
Site Superintendent
Procurement Manager
Risk Manager
Quantity Surveyor
Estimator
Construction Manager
Operations Director
Chief Executive Officer
Architect
Structural Engineer
Building Inspector
Health and Safety Coordinator
Find the exact document you need
Joint Venture Agreement Building (Construction)
Canadian-law governed agreement establishing a joint venture between multiple parties for construction project collaboration, including structure, responsibilities, and risk allocation.
find out more
Owner Builder Contractor Agreement
A Canadian legal agreement between a property owner-builder and contractor establishing terms and conditions for construction projects.
find out more
Agreement For Building Contractor
A Canadian-law governed agreement between property owner and building contractor defining construction project terms, obligations, and deliverables.
find out more
Contractor To Subcontractor Contract
A Canadian legal agreement establishing the terms and conditions between a primary contractor and subcontractor, including work scope, payments, and legal obligations.
find out more
Builder Client Contract
A Canadian jurisdiction contract establishing terms and obligations between builders/contractors and clients for construction projects, compliant with provincial construction laws.
find out more
Land Owner Builder Agreement
A Canadian-law governed agreement between property owners and builders defining construction project terms, obligations, and specifications.
find out more
Contract For House (Construction)
A Canadian-law governed contract establishing terms and conditions between property owner and contractor for residential house construction, including work scope, payments, and compliance requirements.
find out more
Third Party Agreement (Construction)
A Canadian-law governed agreement establishing terms and conditions for third-party construction services, including provincial construction law compliance.
find out more
Project Management Contract In (Construction)
A Canadian-law governed agreement between client and project manager for construction project management services, defining services, responsibilities, and compensation.
find out more
Project Management Agreement (Construction)
A Canadian legal agreement establishing the terms and conditions for professional project management services in construction projects, defining scope, responsibilities, and obligations of the project manager and client.
find out more
Joint Venture Agreement For (Construction)
A Canadian-law governed agreement establishing a joint venture between construction industry partners, defining their collaboration terms and responsibilities.
find out more
Independent Contractor Agreement For (Construction)
Canadian-compliant Independent Contractor Agreement for construction projects, establishing terms for contractor engagement while meeting federal and provincial requirements.
find out more
Contract Between Builder And Homeowner
A Canadian construction agreement between a builder and homeowner outlining project terms, obligations, and compliance with federal and provincial regulations.
find out more
Construction Agreement And Sale Agreement
A Canadian legal agreement combining construction terms and property sale conditions, governing both development and transfer of property.
find out more
Agreement Between Builder And Owner
A Canadian-law governed construction contract between a builder and property owner defining project terms, conditions, and obligations.
find out more
Concrete Contractor Contract
A Canadian-law governed contract between a client and concrete contractor establishing terms for concrete construction services, including scope, specifications, and compliance requirements.
find out more
Contract Between Contractor And Owner
A Canadian legal agreement between a property owner and contractor defining the terms, conditions, and obligations for construction or renovation projects.
find out more
Standard Contractor Contract
A Canadian-law governed agreement establishing the terms and conditions between a company and an independent contractor, ensuring clear relationship definition and mutual protection of interests.
find out more
House Building Contract Agreement
A Canadian-law governed agreement between property owner and contractor for residential house construction, incorporating federal and provincial building requirements.
find out more
Residential Cost Plus Contract
A Canadian residential construction agreement structured on a cost-plus basis, establishing terms for actual costs plus contractor's fee with provincial regulatory compliance.
find out more
Construction Company Partnership Agreement
A Canadian-law governed agreement establishing a partnership between construction industry parties, defining their rights, responsibilities, and operational framework.
find out more
Builder And Land Owner Agreement
A Canadian-law governed agreement between a builder and land owner establishing terms, obligations, and conditions for construction projects.
find out more
Standard General Contractor Agreement
A Canadian-law governed agreement between property owner and general contractor for construction project execution, outlining key terms, conditions, and responsibilities.
find out more
Standard Building Contract
Canadian-law governed building contract establishing terms between owner and contractor for construction projects.
find out more
Construction Equipment Rental Contract
A Canadian law-governed agreement establishing terms and conditions for construction equipment rental, incorporating federal and provincial requirements for equipment operation and safety.
find out more
Contractor Contingency Agreement
Canadian agreement governing performance-based compensation arrangements between companies and independent contractors, with payment contingent on specific achieved outcomes.
find out more
Construction Completion Agreement
A Canadian legal agreement that outlines the terms and conditions for completing outstanding construction work and addressing deficiencies, compliant with provincial construction laws.
find out more
Construction Agreement Between Client And Contractor
A Canadian-law governed agreement between a project owner and contractor establishing terms, conditions, and obligations for construction project execution.
find out more
Builder Purchase Agreement
A Canadian legal agreement between a builder and purchaser for the construction and sale of a new property, outlining construction terms, payments, and warranties.
find out more
Agreement For Construction Of House With Material
A Canadian-law governed agreement for residential house construction, including materials supply, detailing contractor and owner obligations, specifications, and terms.
find out more
Home Improvement Construction Contract
A Canadian-compliant construction contract template for home improvement projects, establishing terms between contractors and homeowners.
find out more
Pre Construction Purchase Agreement
A Canadian legal agreement for purchasing property before construction completion, outlining terms, specifications, and obligations between developer and buyer under provincial regulations.
find out more
New Construction Purchase Agreement
A Canadian legal agreement for the purchase and sale of newly constructed properties, outlining construction specifications, warranties, and closing requirements.
find out more
Construction Finders Fee Agreement
A Canadian-law governed agreement establishing terms for identifying and introducing construction opportunities in exchange for finder's fees.
find out more
Collaboration Agreement For Construction Of Building
A Canadian-law governed agreement establishing collaboration terms between parties involved in building construction, defining roles, responsibilities, and operational procedures.
find out more
Simple Residential Construction Contract
A Canadian residential construction agreement template that governs the relationship between homeowners and contractors for residential building projects.
find out more
Fence Construction Agreement
A Canadian-law governed agreement between property owner and contractor for fence construction services, including terms, specifications, and compliance requirements.
find out more
Construction Disbursement Agreement
A Canadian legal agreement governing the controlled release of construction financing funds, establishing terms and procedures for disbursements during construction phases.
find out more
Landscape Contractor Contract
A Canadian-law governed agreement between a landscape contractor and property owner/manager for landscaping services and maintenance.
find out more
Construction Owner's Representative Contract
A Canadian-law governed agreement establishing the terms and conditions for a construction owner's representative to manage and oversee construction projects on behalf of the property owner.
find out more
ұԾ’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; ұԾ’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)